In North Midland Building Ltd v Cyden Homes Ltd, the Court of Appeal held that an express contractual term allowing an employer to levy liquidated damages for periods of concurrent delay took precedence over a common law principle known as the prevention principle. Background Cyden Homes Limited (CH) employed a contractor, North Midland Building Limited (NMB), to design and build a large house in the Midlands, under a JCT Design and Build construction contract ...
View the PDF version of the August 2018 IP Beacon. Squarely Decided: The Fifth Circuit Sides with Spongebob On May 22, 2018, inViacom Int’l, Inc. v. IJR Captial Invs., LLC, 242 F. Supp.3d 563 (2017), the Fifth Circuit Court of Appeals upheld summary judgment in favor of Viacom International Inc. (Viacom) on its trademark infringement and unfair competition claims against IJR Capital Investments, LLC (IJR) ...
The courts in busy art capitals of the world like London are often called upon to determine disputes over title, provenance, authenticity and attribution of valuable art and artefacts ...
Legislation and agencies 1 What are the main statutes and regulations relating to employment? The Labor Code of the Philippines (Presidential Decree No. 442, as amended) (the Labor Code) and the Omnibus Rules Implementing the Labor Code ...
Two recent cases and a recently-released Internal Revenue Service (IRS) Program Manager Technical Advice Memorandum have sent shockwaves through the voluntary disclosure community. All three developments give offshore account-holders something to cheer. PMTA 2018-13 In previous client alerts, we have discussed the definition of "willfulness" in the context of offshore assets and, more recently, the closing of the Offshore Voluntary Disclosure Program (OVDP) ...
This month, courts have been active in several of the fiduciary breach cases involving 403(b) retirement plans at private universities, including USC, Brown, New York University, the University of Pennsylvania, Duke and Northwestern. We have been closely monitoring these and other lawsuits against fiduciaries of defined contribution plans, and the lessons to be gleaned for avoiding liability ...
Yesterday, the California Supreme Court issued an important decision for employers that rejects the application of the federal de minimis defense to unpaid wage claims arising under California law. In Troester v. Starbucks, Case No. S234969 (July 26, 2018), the Supreme Court held that California law prohibits requiring employees to "routinely work for minutes off the clock without compensation ...
Earlier this year, the European Court of Justice ("CJEU") has thrown out an appeal by Nestlé, which argued that it owns the shape of its famous treat KitKat. Nestlé, the world's largest food and beverage company, has spent more than a decade fighting to trademark the four-fingered wafer shape. However, EJC's most recent ruling could bring an end to the snack's protected European status ...
The drastic changes in the media landscape made over the past years continue to rock the traditional TV sector. Family TV is being replaced rapidly by content online, on demand and on different mobile devices. The global internet video share by consumers is expected to increase from 64% in 2014 to 80% by 2019 (according to Cisco Visual Networking Index: Forecast and Methodology, 2016–2021) ...
In a recent judgement the Court of Justice of the European Union (CJEU) concluded that an administrator of a Facebook fan page has independent obligations under European data protection law, and will be considered joint controller with Facebook for some processing activities ...
As rapid technological changes in the 21st century continue to expand the types and volume of private electronic information, the Fourth Amendment’s privacy protections are evolving. Originally, “Fourth Amendment jurisprudence was tied to common-law trespass” and provided protections against searches of property. See, United States v. Jones, 565 U.S. 400, 405 (2012) ...
Employers may continue to rely on rounding systems that are neutral in policy and in practice. On June 25, 2018, the California Court of Appeal issued its decision in AHMC Healthcare, Inc. v. Superior Court of Los Angeles County (Letona), finding legal an employer's use of a payroll system that automatically rounds employee time up or down to the nearest quarter hour ...
The rule in the case of Royal British Bank v Turquand 1 is commonly known as Turquand’s Rule or the indoor management rule. It stipulates that an “outsider” dealing with a company in good faith is entitled to assume that there has been compliance with the Articles of Association. You can also assume compliance with the by laws of the company and that the “outsider” need not question the formalities of the internal proceedings of a company ...
After a sustained legislative marketing activity that started earlier this year, Government Emergency Ordinance 45/2018 amending and supplementing certain regulatory acts with impact on public procurement was published in the Official Gazette no. 459 ...
Despite its coming into force in 2001, the courts have frequently avoided commenting on the application and interpretation of the Act to Establish a Legal Framework for Information Technologies1 (hereafter the “LFIT Act”), preferring instead to rely on the provisions in the Civil Code of Québec2. In the decision of Benisty v. Kloda3, judge Jacques J ...
On June 1, 2018, the Los Angeles County Superior Court granted a Defendant’s Motion to Compel Individual Arbitrations of the two Plaintiffs’ wage claims, dismissed the class claims and stayed the action with regard to the remaining Private Attorney Generals Act (PAGA) claim. The Court, in Navarrete v. Louis Vuitton, Case No ...
On June 1, 2018, the Los Angeles County Superior Court granted a Defendant’s Motion to Compel Individual Arbitrations of the two Plaintiffs’ wage claims, dismissed the class claims and stayed the action with regard to the remaining Private Attorney Generals Act (PAGA) claim. The Court, in Navarrete v. Louis Vuitton, Case No ...
In a unanimous decision, the California Supreme Court recently addressed the standard to determine whether a worker is an independent contractor or an employee in wage and hour disputes under California’s Industrial Welfare Commission (IWC) wage orders. In Dynamex Operations West, Inc. v ...
This article will focus on the experience in practice and the evolution of privatizations of state and socially owned companies in Serbia in the period of transition and will assess the boundaries of arbitrability of disputes that arise out of the termination of privatization agreements. The term arbitrability will be analysed from a broader perspective, as opposed to the traditional and commonly used meaning of this term - whether a certain dispute is suitable for arbitration ...
“The framework agreement is an agreement whereby the contracting parties define and establish the main rules and conditions that will govern future agreements that will be concluded between them and that are called agreements “for the application” or “for the enforcement” of the framework agreement.” (High Court of Cassation and Justice Decision n0 ...
In the decision in Rustenburg Platinum Mine and SAEWA obo Meyer Bester and Others, the Constitutional Court dealt with the question of whether an employee referring to a colleague as a “swart man” (“black man”), within the facts set out below, constituted misconduct justifying dismissal.The adjacent large 4x4 vehiclesThe employee in this matter, Mr Bester, was employed by the Rustenburg Platinum Mine (the “employer”) ...
In Praxair Distrib., Inc. v. Mallinckrodt Hosp. Prods. IP Ltd., 2016-2616, -2656, in a decision authored by Judge Lourie, the Court of Appeals for the Federal Circuit held that the printed matter doctrine is properly applied during claim construction and can include not just printed matter, but also mental steps ...
On May 21, 2018, the United States Supreme Court issued its 5-4 decision in Epic Systems Corp. v. Lewis, No. 16-285; Ernst & Young LLP v. Morris, No. 16-300; and NLRB v. Murphy Oil USA, Inc., No. 16-307 holding that an employer may require its employees to sign a dispute resolution arbitration agreement that includes an employee’s waiving the right to bring a claim on a class or collective action basis ...
In a much anticipated opinion, the Supreme Court on Monday held that class action waivers in arbitration agreements are enforceable. In a 5-4 decision written by Justice Neil Gorsuch, the Court stated that “Congress has instructed in the Arbitration Act that arbitration agreements providing for individualized proceedings must be enforced, and neither the Arbitration Act’s saving clause nor the NLRA suggests otherwise ...
