In North Midland Building Ltd v Cyden Homes Ltd, the Court of Appeal held that an express contractual term allowing an employer to levy liquidated damages for periods of concurrent delay took precedence over a common law principle known as the prevention principle. Background Cyden Homes Limited (CH) employed a contractor, North Midland Building Limited (NMB), to design and build a large house in the Midlands, under a JCT Design and Build construction contract ...
View the PDF version of the August 2018 IP Beacon. Squarely Decided: The Fifth Circuit Sides with Spongebob On May 22, 2018, inViacom Int’l, Inc. v. IJR Captial Invs., LLC, 242 F. Supp.3d 563 (2017), the Fifth Circuit Court of Appeals upheld summary judgment in favor of Viacom International Inc. (Viacom) on its trademark infringement and unfair competition claims against IJR Capital Investments, LLC (IJR) ...
The courts in busy art capitals of the world like London are often called upon to determine disputes over title, provenance, authenticity and attribution of valuable art and artefacts ...
Legislation and agencies 1 What are the main statutes and regulations relating to employment? The Labor Code of the Philippines (Presidential Decree No. 442, as amended) (the Labor Code) and the Omnibus Rules Implementing the Labor Code ...
The European Court of Justice (CJEU) has ruled that Christian Louboutin’s famous red sole does not consist solely of ashape that significantly increases the value of aproduct, and therefore can be registered as atrademark. This is an important victory for the fashion designer in the long-running battle concerning red-soled shoes ...
Two recent cases and a recently-released Internal Revenue Service (IRS) Program Manager Technical Advice Memorandum have sent shockwaves through the voluntary disclosure community. All three developments give offshore account-holders something to cheer. PMTA 2018-13 In previous client alerts, we have discussed the definition of "willfulness" in the context of offshore assets and, more recently, the closing of the Offshore Voluntary Disclosure Program (OVDP) ...
This month, courts have been active in several of the fiduciary breach cases involving 403(b) retirement plans at private universities, including USC, Brown, New York University, the University of Pennsylvania, Duke and Northwestern. We have been closely monitoring these and other lawsuits against fiduciaries of defined contribution plans, and the lessons to be gleaned for avoiding liability ...
Yesterday, the California Supreme Court issued an important decision for employers that rejects the application of the federal de minimis defense to unpaid wage claims arising under California law. In Troester v. Starbucks, Case No. S234969 (July 26, 2018), the Supreme Court held that California law prohibits requiring employees to "routinely work for minutes off the clock without compensation ...
In the Loop: With the Hanson Bridgett Government Group Not long ago, the state of California suffered through a crippling six-year drought, and water conservation was the name of the game. But California’s last two winters have been wetter, and water conservation feels a lot less urgent when the stuff is literally falling from the sky ...
Earlier this year, the European Court of Justice ("CJEU") has thrown out an appeal by Nestlé, which argued that it owns the shape of its famous treat KitKat. Nestlé, the world's largest food and beverage company, has spent more than a decade fighting to trademark the four-fingered wafer shape. However, EJC's most recent ruling could bring an end to the snack's protected European status ...
As the Trump administration is pushing forward on its deregulatory agenda and, in particular, its efforts to improve the Endangered Species Act (ESA) and its implementation by the US Fish and Wildlife Service (FWS) and National Marine Fisheries Service (NMFS) (together, the Services), the Supreme Court is poised to hear a landmark case on designation of critical habitat under the ESA that could provide some guideposts for the Services’ new regulations ...
Proposition 65 is a 1986 California right-to-know law requiring businesses to provide “clear and reasonable” warnings of potentially harmful exposures to chemicals appearing on the growing list maintained by California’s Office of Environmental Health Hazard Assessment (“OEHHA”) ...
If you sell your products on Amazon, you can benefit from enrolling your trademarks with the Amazon Brand Registry. The Amazon Registry is a free program accessible to monitor brands on Amazon’s website. This program includes proprietary search tools designed specifically to help online merchants identify trademark infringements on Amazon’s platform. If an infringing product is found, the registered owner can request that Amazon remove the product from its website ...
Employers may continue to rely on rounding systems that are neutral in policy and in practice. On June 25, 2018, the California Court of Appeal issued its decision in AHMC Healthcare, Inc. v. Superior Court of Los Angeles County (Letona), finding legal an employer's use of a payroll system that automatically rounds employee time up or down to the nearest quarter hour ...
Earlier this year the U.S. Supreme Court released its much-anticipated opinion inSouth Dakota v. Wayfair, Inc., in which it held that physical presence within a State is no longer a prerequisite to the imposition of liability on out-of-state sellers to collect and remit sales taxes. In doing so, the Court overruled two of its own earlier cases—National Bellas Hess, Inc. v. Department of Revenue of IllinoisandQuill Corp. v. North Dakota ...
The rule in the case of Royal British Bank v Turquand 1 is commonly known as Turquand’s Rule or the indoor management rule. It stipulates that an “outsider” dealing with a company in good faith is entitled to assume that there has been compliance with the Articles of Association. You can also assume compliance with the by laws of the company and that the “outsider” need not question the formalities of the internal proceedings of a company ...
After a sustained legislative marketing activity that started earlier this year, Government Emergency Ordinance 45/2018 amending and supplementing certain regulatory acts with impact on public procurement was published in the Official Gazette no. 459 ...
The Corps Struggles to Balance Competing Constitutional and Statutory Duties Federal agencies must often balance competing policy concerns and legal requirements. This process may be difficult and fraught with intense public feedback, and frequently results in litigation. The U.S. Army Corps of Engineers (the Corps) has found itself in the hot seat over how it manages the nation’s rivers, pitting its obligations under the Endangered Species Act (ESA) against private property rights ...
On June 1, 2018, the Los Angeles County Superior Court granted a Defendant’s Motion to Compel Individual Arbitrations of the two Plaintiffs’ wage claims, dismissed the class claims and stayed the action with regard to the remaining Private Attorney Generals Act (PAGA) claim. The Court, in Navarrete v. Louis Vuitton, Case No ...
On June 1, 2018, the Los Angeles County Superior Court granted a Defendant’s Motion to Compel Individual Arbitrations of the two Plaintiffs’ wage claims, dismissed the class claims and stayed the action with regard to the remaining Private Attorney Generals Act (PAGA) claim. The Court, in Navarrete v. Louis Vuitton, Case No ...
In a unanimous decision, the California Supreme Court recently addressed the standard to determine whether a worker is an independent contractor or an employee in wage and hour disputes under California’s Industrial Welfare Commission (IWC) wage orders. In Dynamex Operations West, Inc. v ...
This article will focus on the experience in practice and the evolution of privatizations of state and socially owned companies in Serbia in the period of transition and will assess the boundaries of arbitrability of disputes that arise out of the termination of privatization agreements. The term arbitrability will be analysed from a broader perspective, as opposed to the traditional and commonly used meaning of this term - whether a certain dispute is suitable for arbitration ...
The first upscale exploration of oil and gas in Montenegro started in 1914, when King Nikola Petrovic approved the National Assembly's decision for oil exploration around Lake Skadar. The first well in the area of Crmnica dates back to 1922 - although it produced nothing of significance. In later researches of the Montenegrin offshore, the existence of geological structures with the potential for hiding hydrocarbon deposits was confirmed ...
Following a tip, the Serbian Competition Commission (the "Commission") recently started investigating the business relationship between GR Sport and Polanik, a Polish company, concerning an alleged infringement of competition – the conclusion of a restrictive agreement which was not notified for prior exemption under the applicable legal framework ...
